1. Definitions and Interpretation.
As used herein, “Agreement” means these Sales Order Terms and Conditions for Sales (the “Terms”), together with the applicable Purchase Order (“PO”) and the applicable Sales Order Acknowledgment (“SOA”); “Carrier” means Buyer or the third party carrier engaged by Buyer to deliver the Products to Buyer’s site, except as otherwise specified in the SOA, “Delivery” means partial or full delivery of the Products to Buyer in accordance with the Terms; “Laws” means all applicable federal, state, and local laws, codes, rules, regulations, and orders of any governmental authority; “Prices” means the prices set forth in the Quotation; “Products” means the goods and materials specified in the PO and confirmed in the SOA; “Quotation” means the quotation submitted by Seller for the sale and delivery of the Products to Buyer; “Services” means installation and maintenance advice provided by Seller to Buyer at Buyer’s site or a location designated by Buyer; and “Shipping Site” means Seller’s plant where the Products are received by the Carrier for transportation to Buyer’s site, as specified in the SOA. In interpreting the Agreement: (a) the singular includes the plural and vice versa; (b) reference to a document or Law means such document or Law as amended from time to time; (c) the term “or” is not exclusive; (d) “include” or “including” means including without limiting the generality of any description preceding such term; (e) headings are for convenience only and do not constitute a part of the Agreement; (f) all references to money refer to United States currency unless otherwise indicated on the SOA; (g) the terms “herein,” “hereunder,” “hereby,” and derivatives or similar words refer to the entire Agreement; and (h) references to Seller are deemed to include affiliates of Seller that provide Products or Services to Buyer.
2. Entire Agreement.
All Deliveries of Products are subject to the Terms, regardless of whether the Terms are attached to a Quotation, PO, SOA, or shipping document or are delivered separately. Buyer shall be deemed to have irrevocably accepted the Terms upon the earliest of (a) delivery of the PO to Seller, (b) acceptance of Delivery of a Product, or (c) payment of any amount due for a Product. A PO is accepted by Seller only upon Seller’s issuance of an SOA. If there are inconsistencies (i) between the Terms and the terms of a PO or an SOA, the Terms shall control, or (ii) between the terms of a PO and the terms of an SOA, the terms of the SOA shall control. If any additional or different terms are contained in the PO or other documentation issued by Buyer (“Proposed Terms”), the Terms shall govern regardless of when the Proposed Terms are received by Seller, unless Seller agrees in writing to the Proposed Terms; otherwise, Seller rejects all Proposed Terms. If the parties have entered into another agreement identified in the SOA (the “Other Agreement Terms”), the Terms and the Other Agreement Terms shall both be applicable where they are not inconsistent with each other; however, to the extent a conflict exists, the Other Agreement Terms shall control.
3. Payment Terms; Late Payments; Security Interest.
Buyer shall pay the amount set forth on each invoice within 30 days after the date thereof. Prices exclude all federal, state, provincial, and local taxes (including sales and use tax), all of which shall be paid by Buyer. Buyer shall not deduct any taxes from any payment unless Seller has confirmed receipt of a valid tax-exempt certificate from Buyer. Past due amounts shall bear interest at the rate of 1 1/2 percent, compounded monthly. Seller may require Buyer to pay all or a portion of the Price, or to provide adequate security for payment of the Price, prior to Delivery of the Products. If Seller makes a Delivery of any Products before Buyer’s payment in full of the Price therefor, then (a) if permitted by Law, Buyer grants to Seller a purchase money security interest in the Products and authorizes Seller to file Uniform Commercial Code financing statements, amendments, and continuation statements or filings under the Canadian Personal Property Security Act in connection therewith and to take all other actions Seller deems necessary or desirable to perfect, maintain, protect, and foreclose on the security interest granted herein, or (b) if Buyer is prohibited by Law from granting a purchase money security interest to Seller, Buyer shall issue to Seller a payment bond in the amount of the unpaid Price promptly upon Delivery of the Products and maintain the bond in full force and effect until the Price is paid in full.
4. Change Orders.
Buyer may modify the quantity or types of Products requested in a PO by the issuance of a change order, so long as the change order is delivered by Buyer prior to shipment of the Products. Seller shall confirm acceptance of a change order by notice to Buyer, which notice may include equitable adjustments in the Prices and Delivery Dates for the affected Products.
5. Shipment; Title; Risk of Loss.
Unless otherwise specified on an SOA, Products shall be delivered Ex-Works Shipping Site, with Buyer responsible for transportation insurance. Buyer shall assume risk of loss of the Products at the Shipping Site, but title to the Products shall remain with Seller until Buyer’s payment of the Price for the Products in full. Buyer shall inventory all Products within 30 days after Delivery, and Buyer shall note any shortages found on the shipping list and on the Bill of Lading. Any shortages shall be claimed by Buyer and addressed by Seller in accordance with the Limited Warranty.
Delivery dates are estimates only. Seller shall attempt to notify Buyer of anticipated Delivery delays, but Seller shall not be in default due to any such delays.
7. Installation; Safety; Insurance.
Except for Services acknowledged in the SOA, Seller shall not install or supervise or otherwise assist Buyer with the installation of Products. Buyer shall be solely responsible for (a) investigating installers and determining the qualifications of installers for particular Products, and (b) compliance by Buyer and any installer with all Laws and standard industry practices during installation, including OSHA standards and requirements and installation codes. Buyer shall carry adequate insurance coverage, including liability and errors and omissions, for risks of loss, damage, and injury before, during, and after installation.
8. Limited Warranty.
Seller warrants that upon Delivery and for a period of one year thereafter (the “Limited Warranty Period”), the Products shall be free of defects in material and workmanship and meet the specifications agreed upon in writing by Seller and Buyer. The Limited Warranty shall not cover noncompliance with the specifications that results from (a) use of Products in other than their normal and customary manner or not in compliance with the instruction materials provided by Seller, (b) neglect, abuse, or misuse, (c) accident, fire, flood, lightening or other acts of God, war, or other events beyond Seller’s reasonable control, (d) improper handling, operation, transport, storage, or environmental conditions, (e) unauthorized alterations or repairs, (f) improper or faulty installation, maintenance, service, or cleaning, including installation, service, cleaning or maintenance not in compliance with standard industry practices or the instruction manuals provided by Seller; (g) damage that occurs during shipment, (h) cosmetic damage, including scratches to exposed parts of the Products, or (i) use of the Product parts that are not Seller parts or parts from Seller-approved vendors. Except for the Limited Warranty, SELLER MAKES NO REPRESENTATIONS OR WARRANTIES, EXPRESS OR IMPLIED, REGARDING THE PRODUCTS, INCLUDING COMPLIANCE WITH BUYER’S OR END-USER’S SPECIFICATIONS AND INDUSTRY STANDARDS; ALL OTHER WARRANTIES, INCLUDING WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, AND DESIGN ARE DISCLAIMED AND EXCLUDED.
Seller shall perform the Services (a) substantially in compliance with all permits, licenses, and third party approvals necessary or desirable for the performance of the Services, all of which shall be obtained by Buyer, Laws, and policies of Buyer regarding safety measures to be taken at the location where the Services are performed, and (b) in a professional manner with the standard of care, skill, and diligence normally provided by a person in the performance of services similar to the Services.
With regard to Products, if, within the Limited Warranty Period, Buyer notifies Seller of any Products that do not comply with the Limited Warranty (“Defective Products”), Seller shall, at its sole option and at no charge to Buyer, repair or replace the Defective Products within a reasonable time after notification. At the sole discretion of Seller, all replaced parts and Products may become the property of Seller upon replacement. With regard to Services, Buyer shall promptly notify Seller of any Services that fail to satisfy the standards set forth in Section 9 (“Defective Services”) and, as Buyer’s sole remedy for Defective Services, at Buyer’s option and at no cost to Buyer, Seller shall correct, re-perform, or refund all payments made by Buyer for Defective Services. EXCEPT AS PROVIDED IN THIS SECTION 10, SELLER SHALL NOT BE LIABLE TO BUYER OR ANY THIRD PARTY FOR (a) ANY LOSS, INCONVENIENCE, OR DAMAGE, WHETHER DIRECT, INCIDENTAL, CONSEQUENTIAL, OR OTHERWISE, INCLUDING LOSS, INCONVENIENCE, OR DAMAGE RESULTING FROM THE INSTALLATION OF REPLACEMENT PRODUCTS, REMOVAL OF DEFECTIVE PRODUCTS, AND TRANSPORTATION OF REPLACEMENT OR DEFECTIVE PRODUCTS, RESULTING FROM ANY BREACH OF THE LIMITED WARRANTY, (b) THE FAILURE OF THE PRODUCTS TO PERFORM TO THE SPECIFICATIONS OR STANDARDS FOR SELLER’S PRODUCTS OR BE FREE FROM DEFECTS IN MATERIAL AND WORKMANSHIP, OR (c) DEFECTIVE SERVICES.
11. Compliance with Laws.
Buyer shall comply with all Laws in effect from time to time relating to the use, handling, transportation, installation, service, maintenance, cleaning, and disposal of the Products.
12. No Liens.
Buyer shall not allow the creation of any lien or security interest on any Products until Seller’s Delivery of the Products and Buyer’s payment in full of the Price for the Products.
Each party (the “Indemnifying Party”) shall indemnify, hold harmless, and if requested by the other party, defend, the other party and its affiliates and their respective employees, officers, directors, shareholders, members, partners, contractors, and consultants, and the successors and assigns of all of the foregoing (as applicable, the “Indemnified Party”) from and against all losses, costs, expenses, liabilities, damages, fines, or penalties, including court costs, reasonable attorneys’ and professionals’ fees and expenses and other litigation or settlement expenses (collectively “Losses”) sustained or incurred by the Indemnified Party, including in connection with a claim, demand, or action (a “Claim”) made by a third party against the Indemnified Party, to the extent arising from (a) failure of the Indemnifying Party to perform the Indemnifying Party’s obligations under the Agreement, (b) if Seller is the Indemnifying Party, the manufacture and use of the Products before Delivery, including injuries to person or property, and (c) if Buyer is the Indemnifying Party, the installation and use of the Products after Delivery, including injuries to person or property before, during, and after installation of the Products.
14. Reciprocal Disclaimer of Consequential Damages.
Neither party shall be liable to the other for any amounts representing the other party’s loss of profits, loss of business, or other indirect, special, exemplary, consequential, or punitive damages, arising from the performance or nonperformance of the Agreement.
All notices, consents, approvals, change orders, and other communications that are required or permitted to be given under the Agreement shall be sufficient in all respects if given in writing and delivered in person or by electronic mail, facsimile, overnight courier, or certified mail, postage prepaid, return receipt requested, to the receiving party at the address shown on the SOA, or to such other address as such party may have given to the other by notice pursuant to this Section. Notices, consents, approvals, change orders, and other communications shall be deemed delivered, given, and received on the date of delivery, in the case of personal delivery, electronic mail, or facsimile, or on the delivery or refusal date, as specified on the return receipt in the case of certified mail or on the tracking report in the case of overnight courier.
16. Governing Law and Forum.
The Laws of the State of Wyoming, excluding choice of law rules, shall govern any action related to the Agreement. Any litigation with respect to the Agreement shall be brought in the courts of the State of Wyoming, County of Laramie, and Buyer irrevocably submits to such personal jurisdiction and venue.
17. Attorney’s Fees.
If Seller is required to take any action to enforce the terms of the Agreement, Seller shall be entitled to reasonable attorneys’, consultants’, expert witnesses’, and other professionals’ fees and costs, costs of collection, and interest at the statutory rate on any unpaid amount from the date due.
18. Force Majeure.
A party that fails to perform its obligations under the Agreement (other than failure to make payments when due) shall be free from liability for failing to perform if such failure is caused due to acts of God, labor difficulties, fires, or other causes beyond the reasonable control of the affected party.
19. No Waiver; Amendments; No Assignment; Severability.
No delay in exercising or failure to exercise a right of remedy shall impair that or any other right or remedy or be construed as a waiver of any such right or remedy. The Agreement (a) may be amended or cancelled only in writing signed by both parties, and (b) may not be assigned by Buyer without Seller’s prior consent, and any attempt to assign it without such consent shall be absolutely void. If any of the provisions herein shall for any reason be held void or unenforceable, the remaining provisions shall remain in full force and effect.